EFTA00520727.pdf

NMI Payment Gateway Page 1 of I Transaction Successful Transaction Receipt Merchant: Artistic Tile A.D. Building - (New York, NY) Date/Time: 12/19 2011 3:03:28 PM EST Transaction ID: 298 Transaction Type: Card Sale Amount: 2,307.16 Credit card Info CC Type: American Express CC Number: 3014 Auth. Code: 244886 Billing Information Shipping Information 301 E 66TH STREET APT 14G NEW YORK NY, 10065 US Order Information Order ID: 544908 Description: Tax: 204.76 I agree reement. Thank you for your order. Note: As a reminder, custom orders cannot be cancelled, exchanged, or returned. Artistic Tile A.D. Building 150 East 58th St New York, NY 10155 https://secure.networicmerchants.com/merchants/rectiptphp?tid=14c5cbef37e7c8ed66a8... 12/19/2011 EFTA00520727 ARTISTIC TILE Page 1 d 4 150 E. 58th STREET NEW YORK NY 155 TEL FAX Sold To: 301 E 66TH STREET APT 14G TELEPHONE 3 New York. NY 10065 CUSTOMER P.O. SHIP VIA F.O.B. TERMS: BALANCE DUE PRIOR TO DELIVERY SHIP DATE 12/162011 ITEM NUMBER UNIT I ORDERED I i SHIPPED BACKORDER PRICE SIDEMARK I AMOUNT BRINGING ART TO LIFE SALES ORDER SO ORDER #: ORDER DATE: CUSTOMER #: SALESPERSON: Shf To: 301 E 66TH STREET APT 2G New York, NY 10065 0544908 12/19/2011 CAROLINE CHOY-SHAN ILE TAX ON US PROMO ESCHH12 S/F 40.000 0.000 0 000 9.975 399.00 CHAMPAGNE HONED 1TX12-X3/8" STRAIGHT EDGE 10 PCS/BOX, 36 BOXES/CRATE, 360 SF/CRATE MUST SEAL ECDVWHG3X6 S/F 202.500 0.000 0.000 S 063 1,632.76 DOVER WHITE 3X6X5/16 GLOSS FIELD 0.125 SF1PCS 7.50 SF/BOX VENDOR REF: DOVWHIT36 EAOSCQT EACH 2.000 0.000 0.000 75.200 150.40 STONE SEALERS CHOICE QUART WATER BASED 12 OTS/CS 32 OUNCE BOTTLE PREMIUM. WATER-BASED, NO SHEEN. NATURAL LOOK PENETRATING SEALER. PROVIDES MAXIMUM STAIN PROTECTION. ESPECIALLY IN FOOD PREPARATION AND SERVING AREAS, LASTS UP TO 15 YEARS. /PACK 10.00 PACKING CHARGE ROUTE TRUCK DELIVERY - ANY OTHER METHOD WILL INCREASE FREIGHT CHARGES EFTA00520728 ARTISTIC TILE Page 3 of 4 150 E. 58th STREET NEW YORK, NY 10155 TEL FAX Sold To: 301 E 66TH STREET APT 14G TELEPHONE 3 New York, NY 10065 BRINGING ART TO LIFE SALES ORDER SO ORDER #: ORDER DATE: CUSTOMER #: SALESPERSON: CAROLINE CHOY-SHAN Shi To: 301 E 66TH STREET APT 2G New York. NY 10065 0544908 12/19/2011 CUSTOMER P.O. ITEM NUMBER SHIP VIA 1F.O.B. TERMS: BALANCE DUE PRIOR TO DELIVERY SHIP DATE 12/16/2011 UNIT I ORDERED SHIPPED BACKORDER, PRICE SIDEMARK AMOUNT Thank you for choosing Artistic Tile. Quotes/sales order prices are valid for 30 days from quote/sales order date. Please inspect your shipment immediately for size. color, shade. finish or de ects. Claims for product defects, shipping damage, or shortage must be made win 48 hours of receipt. Installation of material constitutes acceptance. Installed material of any kind is not refundable. Client specifically & knowingly waives any & all warranties, including, but not limited to the warranty of merchantability. Shade & nominal size variations are natural characteristics of tile & stone; actual material may differ in shading from samples. Special orders are non-cancellable, as well as non-returnable. Artistic Tile stocked items may be returned for credit within 90 days of receipt, while non-branded Artistic Tile product is subject to a 35% restock charge, if accepted for return. All returns incur freight costs billed to the customer. Before signing this sales order, review the full Conditions of Sale that follow separately. Your signature will confirm you acknowledge & accept the Conditions of Sale. A signature on a quote confirms it as a sales ord SIGNATU DAT Now that you are part of the Artistic Tile family, Net Order: 2,192.16 Freight: 115.00 NY-N.Y.CITY-8.875 204.76 % - Sales Tax: Order Total: 2,511.92 an us at www.facebook.com/ARTISTICTILE EFTA00520729 Conditions of Sale 12/13/2010 Thank you for choosi ng Artistic Tile as the provider of you luxury tile & stone. Please read & So our Conditions of Sale prior la purchase. & be sure you & your installer or other agents are aware of the unique logistical & technical issues associatedwith anytile or stone purchase. delivery & installation. This document is a contract, so reading it carefully & asking your Aristc Tile associate if you have any questions v41 ensure a worry-free experience. Scope of work: Artistic Tile, Inc. is not a contractor & does not perform or contract for the installation of any product As a courtesy to its cients upon request Artistic Tile, Inc. vii provide a list of local licensed contractors & tile installers. This kst sha0 serve as a recomrrendation only. Absent any specific instructions, generally accepted industry guidel MS must be adhered to, including, but not limited to. Tie Council of North America handbook & Marble Institute of America Dimensional Stone Design Manual Quantities Al quantities must be verified in advance of purchase by the buyer's tae installer or general contractor. Artistic Tile, kin accepts no responsibiity for quantities ordered. However, as a service to our clients, once you have selected your desi gn, our associate will provide you with takeoff quantities forest mating Imposes, & will rake every attempt to directly contact the instal ler for the final specification quantities of each item. Product information: All tile is subject to variation in shade &stet All tile measurements are nominal Tile & stone are not guaranteed after del 'very against chipping, crazing, cracking or wear. All stone & crackle glaze ceramic tile must he sealed. Ceranticipoicelainrglass: Handmade & machine made tile is subject to irregularities in size. shape, color, warpage, moisture absorption, surface finish. texture & coefident of friction. These characteristics are inherent to the manufacture of theseproducts &are in pat what creats their distinctive beauty. Stone is a natural material. There will be color variation frOM Sant let & displays, as well as within your shipment No two pieces of stone are exactly alike. Each has unique natural variations which may include veining. markings, shadings, inclusions, dips, pits, or fossils. We recommend that each order include a rrininum of 20% overage on any Ile product. Blending and Dry Lay Out: Because of their nature which includes multiple types of variation, natural stone & ceramic tile require et/ending. It is the responsibity of the installer to dry lay out all materials & obtain the customers approval of the blend before any tile is thstaled. This procedure is common practice in the i nstallati on of tile & stone & helps ensure the beauty of the finished installation. Artistic Tile. Inc. ants our cusbnram to be deighted with their finished rooms, so the above mentioned factors should be considered by the customer prior to making the purchase decision. Payment Tema: Payment in-full, with tax & freight, is required prior to delivery. Payment in-full on orders of 52000 or less is required at time of sale. Stocked material: e Must be paid in-full 30days atter initial deposit. • Material not in stock at tine of deposit must be paid in-full 30-days from product receipt at our varehouse. Orders for stocked goods are not cancelable ater 60-days. Custom material: • Due to quick lead-tare, full payment is required at time of sale on Artistic Tile in-house production and custom glass orders. e Custom orders are not cancebble. exchangeable, or returnable after placement. Artistic Tile. Inc. mill store completed paid in-full orders free of charge until delivery is scheduled for up to 4-men Ohs alter order placement, After 4- months, storage fees we billed 525per pallet per month. Ali materials & payments will be forfeited if delivery is not taken within one year. Shipping: All products are shipped via common carrier. not by Artiste Tile, Inc. Ail Shipments are FOB Destination (please note FOB requirements below) Freight: Freight and packing dirges are added to Sales Orders/Invoices FOB Inspection Requirements e Be careful to verify box count before signing the be! of lading & note any box count discrepancies immediately on the bill of lading before signing it. • You andror your on•site representatives (general contractor. subcontractors, installer &any person responsible to the property owner regarding the installation of the product) must fully open & inspect all merchandise upon delivery to the jobSite. In the event that any discrepancy or concealed damage is discovered, you must nobly the carrier & Artistic Tie, Inc. in writing within 48 hours of delivery. Artistic Tile wil make claim di rectlywith the carrier within 48 hours of delivery. Artistic Tit Inc. WI not be responsible for reimbursement on claims denied due to d Tent's failure to note exceptions. noreGents failure to notify us within 48 hours from delivery date nor due to a client representative's negligence. RetumsCancellatio ns: • Artistic Tile braided stocked items nay be returned for credit within SO-days of receipt Client is responsible for height back to the point of engirt • Materials sold by full carton must be returned as such in original packaging. • All returns must be property packed. Tiles received that are broken, damaged or installed will not be credited. • Custom, trade to order, or special order products are non cancelable & non returnable. • Al returns must be authorized in advance by Artistic Tile, Inc.A copy of the Return Goods Authorization must accompany the return for credit to be issued. • Installed material is not returnable: instal tation whether full or partial constitutes acceptance. • Material that has been hand selected or culled through may not be returned. • All material that is Non-Artistic Tile brand is subject to a 35% restock charge plus freight back to point of origin. These materials may not be returned to our Secau an, NJ warehouse for credit Please consult with your Artistic Tile associate to determine if any of the items you have selected are non- stock prior to purchase. Warrantees: Artistic Tile. Inc. extends no warrantees beyond the manufacturers' Niarraniees. Any & all warranties are -eva rved. including, but not tatted to, the warranty of merchantability. Artistic Tile, Inc. bears no re poresibil ity beyond the price paid by the customer or materials received by the customer. Delays: Artistic Tile, Inc. shall not be responsible fordelivery delays caused by acts of God, shims, accidents. borderecustom delays traffic, natural catastrophes or otherdelays which are beyond our control. Artistic Tile. Inc. reserves the right to delay the processing of this order until the order form anceor the credit card charge receipt have been signed. This (Agreement] shall be exclusively construed in accordance with and governed by the menial laws of the State of New Jersey, without regard to any conflicts of laws provisions. Any suit, action, or proceeding arising out of, or relating to this [Agreement,] must. and exdusieelystial, be commenced and maintained in the Superior Court of the State of New Jersey, County of Bergen. or in tie FederalDistrict Court for the District of New JerSey. located in Newark, NewJersey, and each Party consents to such jurisdiction and venue. Service of process in any such suit, action, or proceeding shat be deemed sufficient and binding if served by certified rmil at the addresses set forth at the beginning of this Agreement. The prevailing party in any such proceeding, or in any proceeding filed to enforce the terms of this Agreement shall be entitled to recover from the non-prevailing party its costs, including reasonable attorneys' fees, incurred in connection with such proceeding. What your signalise means: By signing this order ckent agrees that it accurately reflects the buyer's wishes. Al changes or revisions to this order must be in wrib ng, & a new order form reflecting those changes must be signed before changes or cancelations will be processed. Thank you for choosing Artistic Tile. EFTA00520730